§832.111-70. VA contract clauses for non-commercial purchases.
48 C.F.R. § 832.111-70
Insert the clause at 852.232-70, Payments Under Fixed-Price Construction Contracts (Without NAS-CPM) in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract does not require use of the “Network Analysis System—Critical Path Method (NAS-CPM).”
If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.
Insert the clause at 852.232-71, Payments Under Fixed-Price Construction Contracts (Including NAS-CPM), in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract requires use of the “Network Analysis System—Critical Path Method (NAS-CPM).”
If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.
Notes, amendments, and revision history
Amendments
[83 FR 49306, Oct. 1, 2018]
Authority
Authority: 40 U.S.C. 121(c); 41 U.S.C. 1303; 41 U.S.C. 1702; and 48 CFR 1.301 through 1.304.
Source
Source: 73 FR 2717, Jan. 15, 2008, unless otherwise noted.
Amendments
[83 FR 49306, Oct. 1, 2018]