§42.1302. Suspension of work.
48 C.F.R. § 42.1302
A suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. If the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance, excluding profit.
Notes, amendments, and revision history
Source
Source: 48 FR 42159, Sept. 19, 1983, unless otherwise noted. Redesignated at 60 FR 48241, Sept. 18, 1995.
Authority
Authority: 41 U.S.C. 1121(b); 40 U.S.C. 121(c); 10 U.S.C. chapter 4 and 10 U.S.C. chapter 137 legacy provisions (see 10 U.S.C. 3016); and 51 U.S.C. 20113.
Source
Source: 48 FR 42370, Sept. 19, 1983, unless otherwise noted.