§246.470-1. Assessment of additional costs.
48 C.F.R. § 246.470-1
Under the clause at FAR 52.246-2, Inspection of Supplies—Fixed-Price, after considering the factors in paragraph (c) of this subsection, the quality assurance representative (QAR) may believe that the assessment of additional costs is warranted. If so, the representative shall recommend that the contracting officer take the necessary action and provide a recommendation as to the amount of additional costs. Costs are based on the applicable Federal agency, foreign military sale, or public rate in effect at the time of the delay, reinspection, or retest.
If the contracting officer agrees with the QAR, the contracting officer shall—
Notify the contractor, in writing, of the determination to exercise the Government's right under the clause at FAR 52.246-2, Inspection of Supplies—Fixed-Price; and
Demand payment of the costs in accordance with the collection procedures contained in FAR Subpart 32.6.
In making a determination to assess additional costs, the contracting officer shall consider—
The frequency of delays, reinspection, or retest under both current and prior contracts;
The cause of such delay, reinspection, or retest; and
The expense of recovering the additional costs.
Notes, amendments, and revision history
Amendments
[71 FR 27647, May 12, 2006]
Authority
Authority: 41 U.S.C. 1303 and 48 CFR chapter 1.
Source
Source: 56 FR 36460, July 31, 1991, unless otherwise noted.
Amendments
[71 FR 27647, May 12, 2006]