§5.5. Contract provisions and related matters. — Inbound Citations

(a) Section 1606 of the Recovery Act requires that all laborers and mechanics employed by contractors and subcontractors on projects funded directly by or assisted in whole or in part by and through the Federal Government pursuant to the Recovery Act shall be paid wages at rates not less than those prevailing on projects of a character similar in the locality as determined by the Secretary of Labor in accordance with subchapter IV of chapter 31 of title 40, United States Code.

Pursuant to Reorganization Plan No. 14 and the Copeland Act, 40 U.S.C. 3145, the Department of Labor has issued regulations at 29 CFR parts 1, 3, and 5 to implement the Davis-Bacon and related Acts. Regulations in 29 CFR 5.5 instruct agencies concerning application of the standard Davis-Bacon contract clauses set forth in that section. Federal agencies providing grants, cooperative agreements, and loans under the Recovery Act shall ensure that the standard Davis-Bacon contract clauses found in 29 CFR 5.5(a) are incorporated in any resultant covered contracts that are in excess of $2,000 for construction, alteration or repair (including painting and decorating).

(a) YouthBuild programs and grantees are subject to Davis-Bacon labor standards requirements under the circumstances set forth in paragraph (b) of this section. In those instances where a grantee is subject to Davis-Bacon requirements, the grantee must follow applicable requirements in the Department's regulations at 29 CFR parts 1, 3, and 5, including the requirements contained in the Davis-Bacon contract provisions set forth in 29 CFR 5.5.

(a) In cases other than those forwarded to the Attorney General of the United States under paragraph (b) of this section where violations of the labor standards clauses contained in § 5.5 and the applicable statutes referenced by § 5.1 result in underpayment of wages to workers or monetary damages caused by violations of § 5.5(a)(11) or (b)(5), the Federal agency or an authorized representative of the Department of Labor will request that restitution be made to such workers or on their behalf to plans, funds, or programs for any type of bona fide fringe benefits within the meaning of 40 U.S.C. 3141(2)(B), including interest from the date of the underpayment or loss. Interest on any back wages or monetary relief provided for in this part will be calculated using the percentage established for the underpayment of taxes under 26 U.S.C. 6621 and will be compounded daily.

(2) [Reserved]

Agency Head. The term “Agency Head” means the principal official of an agency and includes those persons duly authorized to act on behalf of the Agency Head.

Apprentice and helper. The terms “apprentice” and “helper” are defined as follows:

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(i) The Federal agency has the initial responsibility to ascertain whether the clauses required by § 5.5 and the appropriate wage determination(s) have been incorporated into the contracts subject to the labor standards provisions of the laws referenced by § 5.1. Additionally, a Federal agency that provides Federal financial assistance that is subject to the labor standards provisions of the Act must promulgate the necessary regulations or procedures to require the recipient or sub-recipient of the Federal assistance to insert in its contracts the provisions of § 5.5. No payment, advance, grant, loan, or guarantee of funds will be approved by the Federal agency unless it ensures that the clauses required by § 5.5 and the appropriate wage determination(s) are incorporated into such contracts. Furthermore, no payment, advance, grant, loan, or guarantee of funds will be approved by the Federal agency after the beginning of construction unless there is on file with the Federal agency a certification by the contractor that the contractor and its subcontractors have complied with the provisions of § 5.5 or unless there is on file with the Federal agency a certification by the contractor that there is a substantial dispute with respect to the required provisions.

(ii) If a contract subject to the labor standards provisions of the applicable statutes referenced by § 5.1 is entered into without the incorporation of the clauses required by § 5.5, the agency must, upon the request of the Administrator or upon its own initiative, either terminate and resolicit the contract with the required contract clauses, or incorporate the required clauses into the contract (or ensure they are so incorporated) through supplemental agreement, change order, or any and all authority that may be needed. Where an agency has not entered directly into such a contract but instead has provided Federal financial assistance, the agency must ensure that the recipient or sub-recipient of the Federal assistance similarly incorporates the clauses required into its contracts. The method of incorporation of the correct wage determination, and adjustment in contract price, where appropriate, should be in accordance with applicable law. Additionally, the following requirements apply:

(A) Unless the Administrator directs otherwise, the incorporation of the clauses required by § 5.5 must be retroactive to the date of contract award or start of construction if there is no award.

(B) If this incorporation occurs as the result of a request from the Administrator, the incorporation must take place within 30 days of the date of that request, unless the agency has obtained an extension from the Administrator.

(C) The contractor must be compensated for any increases in wages resulting from incorporation of a missing contract clause.

(D) If the recipient refuses to incorporate the clauses as required, the agency must make no further payment, advance, grant, loan, or guarantee of funds in connection with the contract until the recipient incorporates the required clauses into its contract, and must promptly refer the dispute to the Administrator for further proceedings under § 5.13.

(E) Before terminating a contract pursuant to this section, the agency must withhold or cross-withhold sufficient funds to remedy any back wage liability resulting from the failure to incorporate the correct wage determination or otherwise identify and obligate sufficient funds through a termination settlement agreement, bond, or other satisfactory mechanism.

(F) Notwithstanding the requirement to incorporate the contract clauses and correct wage determination within 30 days, the contract clauses and correct wage determination will be effective by operation of law, retroactive to the beginning of construction, in accordance with § 5.5(e).

(a) In the event of failure or refusal of the contractor or any subcontractor to comply with the applicable statutes referenced by § 5.1 and the labor standards clauses contained in § 5.5, whether incorporated into the contract physically, by reference, or by operation of law, the Federal agency (and any other agency), may, upon its own action, or must, upon written request of an authorized representative of the Department of Labor, take such action as may be necessary to cause the suspension of the payment, advance, or guarantee of funds until such time as the violations are discontinued and/or until sufficient funds are withheld as may be considered necessary to compensate workers for the full amount of wages and monetary relief to which they are entitled, and to cover any liquidated damages and pre-judgment or post-judgment interest which may be due.

(a) Section 1606 of the Recovery Act requires that all laborers and mechanics employed by contractors and subcontractors on projects funded directly by or assisted in whole or in part by and through the Federal Government pursuant to the Recovery Act shall be paid wages at rates not less than those prevailing on projects of a character similar in the locality as determined by the Secretary of Labor in accordance with subchapter IV of chapter 31 of title 40, United States Code.

Pursuant to Reorganization Plan No. 14 and the Copeland Act, 40 U.S.C. 3145, the Department of Labor has issued regulations at 29 CFR parts 1, 3, and 5 to implement the Davis-Bacon and related Acts. Regulations in 29 CFR 5.5 instruct agencies concerning application of the standard Davis-Bacon contract clauses set forth in that section. Federal agencies providing grants, cooperative agreements, and loans under the Recovery Act shall ensure that the standard Davis-Bacon contract clauses found in 29 CFR 5.5(a) are incorporated in any resultant covered contracts that are in excess of $2,000 for construction, alteration or repair (including painting and decorating).

All contracts made with respect to the construction, prosecution, completion, or repair of any public building or public work or building or work financed in whole or in part by loans or grants from the United States covered by the regulations in this part must expressly bind the contractor or subcontractor to comply with such of the regulations in this part as may be applicable. In this regard, see § 5.5(a) of this subtitle. However, these requirements will be considered to be effective by operation of law, whether or not they are incorporated into such contracts, as set forth in § 5.5(e) of this subtitle.

(b) The Agency Head must cause or require the contracting officer to insert the following clauses set forth in paragraphs (b)(1) through (5) of this section in full, or (for contracts covered by the Federal Acquisition Regulation) by reference, in any contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses must be inserted in addition to the clauses required by paragraph (a) of this section or 29 CFR 4.6. As used in this paragraph (b), the terms “laborers and mechanics” include watchpersons and guards.

(1) No contractor or subcontractor contracting for any part of the conract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.

(2) In the event of any violation of the clause set forth in paragraph (b)(1) of this section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages and interest from the date of the underpayment. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchpersons and guards, employed in violation of the clause set forth in paragraph (b)(1) of this section, in the sum of $33 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (b)(1).

(i) The [write in the name of the Federal agency or the recipient of Federal assistance] may, upon its own action, or must, upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the contractor so much of the accrued payments or advances as may be considered necessary to satisfy the liabilities of the prime contractor or any subcontractor for any unpaid wages; monetary relief, including interest; and liquidated damages required by the clauses set forth in this paragraph (b) on this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract subject to the Contract Work Hours and Safety Standards Act that is held by the same prime contractor (as defined in § 5.2). The necessary funds may be withheld from the contractor under this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract that is subject to the Contract Work Hours and Safety Standards Act and is held by the same prime contractor, regardless of whether the other contract was awarded or assisted by the same agency, and such funds may be used to satisfy the contractor liability for which the funds were withheld.

(ii) The Department has priority to funds withheld or to be withheld in accordance with paragraph (a)(2)(i) or (b)(3)(i) of this section, or both, over claims to those funds by:

(A) A contractor's surety(ies), including without limitation performance bond sureties and payment bond sureties;

(B) A contracting agency for its reprocurement costs;

(C) A trustee(s) (either a court-appointed trustee or a U.S. trustee, or both) in bankruptcy of a contractor, or a contractor's bankruptcy estate;

(D) A contractor's assignee(s);

(E) A contractor's successor(s); or

(F) A claim asserted under the Prompt Payment Act, 31 U.S.C. 3901-3907.

(4) The contractor or subcontractor must insert in any subcontracts the clauses set forth in paragraphs (b)(1) through (5) of this section and a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor is responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (b)(1) through (5). In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and associated liquidated damages and may be subject to debarment, as appropriate.

(5) It is unlawful for any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, or to cause any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, any worker or job applicant for:

(i) Notifying any contractor of any conduct which the worker reasonably believes constitutes a violation of the Contract Work Hours and Safety Standards Act (CWHSSA) or its implementing regulations in this part;

(ii) Filing any complaint, initiating or causing to be initiated any proceeding, or otherwise asserting or seeking to assert on behalf of themselves or others any right or protection under CWHSSA or this part;

(iii) Cooperating in any investigation or other compliance action, or testifying in any proceeding under CWHSSA or this part; or

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(b) The rate of contribution or cost is ordinarily an hourly rate, and will be reflected in the wage determination as such. In some cases, however, the contribution or cost for certain fringe benefits may be expressed in a formula or method of payment other than an hourly rate. In such cases, the Secretary may in his discretion express in the wage determination the rate of contribution or cost used in the formula or method or may convert it to an hourly rate of pay whenever he finds that such action would facilitate the administration of the Act. See § 5.5(a)(1)(i) and (iii).

(5) For Federal-aid highway projects under 23 U.S.C. 113, information obtained from the highway department(s) of the State(s) in which the project is to be performed. For such projects, the Administrator must consult the relevant State highway department and give due regard to the information thus obtained.

(4) Wage rate data submitted to the Department of Labor by contracting agencies pursuant to § 5.5(a)(1)(iii) of this subtitle.

(b) The rate of contribution or cost is ordinarily an hourly rate, and will be reflected in the wage determination as such. In some cases, however, the contribution or cost for certain fringe benefits may be expressed in a formula or method of payment other than an hourly rate. In such cases, the Secretary may in his discretion express in the wage determination the rate of contribution or cost used in the formula or method or may convert it to an hourly rate of pay whenever he finds that such action would facilitate the administration of the Act. See § 5.5(a)(1)(i) and (iii).

(iii) A “helper” classification will be added to wage determinations pursuant to § 5.5(a)(1)(iii)(A) only where, in addition, the work to be performed by the helper is not performed by a classification in the wage determination.

Building or work. The term “building or work” generally includes construction activities of all types, as distinguished from manufacturing, furnishing of materials, or servicing and maintenance work. The term includes, without limitation, buildings, structures, and improvements of all types, such as bridges, dams, solar panels, wind turbines, broadband installation, installation of electric car chargers, plants, highways, parkways, streets, subways, tunnels, sewers, mains, power lines, pumping stations, heavy generators, railways, airports, terminals, docks, piers, wharves, ways, lighthouses, buoys, jetties, breakwaters, levees, canals, dredging, shoring, rehabilitation and reactivation of plants, scaffolding, drilling, blasting, excavating, clearing, and landscaping. The term “building or work” also includes a portion of a building or work, or the installation (where appropriate) of equipment or components into a building or work.

Construction, prosecution, completion, or repair. The term “construction, prosecution, completion, or repair” means the following:

(c) To receive approval of an unfunded plan or program, a contractor or subcontractor must demonstrate in its request to the Secretary that the unfunded plan or program, and the benefits provided under such plan or program, are “bona fide,” meet the requirements set forth in paragraphs (b)(1) through (4) of this section, and are otherwise consistent with the Act. The request must include sufficient documentation to enable the Secretary to evaluate these criteria. Contractors and subcontractors may request approval of an unfunded plan or program by submitting a written request in one of the following manners:

(1) By mail to the United States Department of Labor, Wage and Hour Division, Director, Division of Government Contracts Enforcement, 200 Constitution Ave. NW, Room S-3502, Washington, DC 20210;

(2) By email to [email protected] (or its successor email address); or

(3) By any other means directed by the Administrator.

(d) The legislative reports indicate that, to insure against considering and giving credit to any and all fringe benefits, some of which might be illusory or not genuine, the qualification was included that such fringe benefits must be “bona fide” (H. Rep. No. 308, p. 4; S. Rep. No. 963, p. 6). No difficulty is anticipated in determining whether a particular fringe benefit is “bona fide” in the ordinary case where the benefits are those common in the construction industry and which are established under a usual fund, plan, or program. This would be typically the case of those fringe benefits listed in paragraph (a) of this section which are funded under a trust or insurance program. Contractors may take credit for contributions made under such conventional plans without requesting the approval of the Secretary of Labor under § 5.5(a)(1)(iv).

(A) All regular payrolls and other basic records must be maintained by the contractor and any subcontractor during the course of the work and preserved for all laborers and mechanics working at the site of the work (or otherwise working in construction or development of the project under a development statute) for a period of at least 3 years after all the work on the prime contract is completed.

(B) Such records must contain the name; Social Security number; last known address, telephone number, and email address of each such worker; each worker's correct classification(s) of work actually performed; hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in 40 U.S.C. 3141(2)(B) of the Davis-Bacon Act); daily and weekly number of hours actually worked in total and on each covered contract; deductions made; and actual wages paid.

(C) Whenever the Secretary of Labor has found under paragraph (a)(1)(v) of this section that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in 40 U.S.C. 3141(2)(B) of the Davis-Bacon Act, the contractor must maintain records which show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits.

(D) Contractors with apprentices working under approved programs must maintain written evidence of the registration of apprenticeship programs, the registration of the apprentices, and the ratios and wage rates prescribed in the applicable programs.

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(c) Cross-withholding of funds may be requested from contracts held by other entities that may be considered to be the same prime contractor as that term is defined in § 5.2. Such cross-withholding is appropriate where the separate legal entities have independently consented to it by entering into contracts containing the withholding provisions at § 5.5(a)(2) and (b)(3). Cross-withholding from a contract held by a different legal entity is not appropriate unless the withholding provisions were incorporated in full or by reference in that different legal entity's contract. Absent exceptional circumstances, cross-withholding is not permitted from a contract held by a different legal entity where the Davis-Bacon labor standards were incorporated only by operation of law into that contract.

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(3) The Federal agency will cause such investigations to be made as may be necessary to assure compliance with the labor standards clauses required by § 5.5 and the applicable statutes referenced in § 5.1. Investigations will be made of all contracts with such frequency as may be necessary to assure compliance. Such investigations will include interviews with workers, which must be taken in confidence, and examinations of certified payrolls, regular payrolls, and other basic records required to be maintained under § 5.5(a)(3). In making such examinations, particular care must be taken to determine the correctness of classification(s) of work actually performed, and to determine whether there is a disproportionate amount of work by laborers and of apprentices registered in approved programs. Such investigations must also include evidence of fringe benefit plans and payments thereunder. Federal agencies must give priority to complaints of alleged violations.

(A) The contractor or subcontractor must submit weekly, for each week in which any DBA- or Related Acts-covered work is performed, certified payrolls to the [write in name of appropriate Federal agency] if the agency is a party to the contract, but if the agency is not such a party, the contractor will submit the certified payrolls to the applicant, sponsor, owner, or other entity, as the case may be, that maintains such records, for transmission to the [write in name of agency]. The prime contractor is responsible for the submission of all certified payrolls by all subcontractors. A contracting agency or prime contractor may permit or require contractors to submit certified payrolls through an electronic system, as long as the electronic system requires a legally valid electronic signature; the system allows the contractor, the contracting agency, and the Department of Labor to access the certified payrolls upon request for at least 3 years after the work on the prime contract has been completed; and the contracting agency or prime contractor permits other methods of submission in situations where the contractor is unable or limited in its ability to use or access the electronic system.

(B) The certified payrolls submitted must set out accurately and completely all of the information required to be maintained under paragraph (a)(3)(i)(B) of this section, except that full Social Security numbers and last known addresses, telephone numbers, and email addresses must not be included on weekly transmittals. Instead, the certified payrolls need only include an individually identifying number for each worker (e.g., the last four digits of the worker's Social Security number). The required weekly certified payroll information may be submitted using Optional Form WH-347 or in any other format desired. Optional Form WH-347 is available for this purpose from the Wage and Hour Division website at https://www.dol.gov/sites/dolgov/files/WHD/legacy/files/wh347/.pdf or its successor website. It is not a violation of this section for a prime contractor to require a subcontractor to provide full Social Security numbers and last known addresses, telephone numbers, and email addresses to the prime contractor for its own records, without weekly submission by the subcontractor to the sponsoring government agency (or the applicant, sponsor, owner, or other entity, as the case may be, that maintains such records).

(i) Certified payrolls submitted pursuant to § 5.5(a)(3)(ii) must be preserved by the Federal agency for a period of 3 years after all the work on the prime contract is completed, and must be produced at the request of the Department of Labor at any time during the 3-year period, regardless of whether the Department of Labor has initiated an investigation or other compliance action.

(ii) In situations where the Federal agency does not itself maintain certified payrolls required to be submitted pursuant to § 5.5(a)(3)(ii), upon the request of the Department of Labor the Federal agency must ensure that such certified payrolls are provided to the Department of Labor. Such certified payrolls may be provided by the applicant, sponsor, owner, or other entity, as the case may be, directly to the Department of Labor, or to the Federal agency which, in turn, must provide those records to the Department of Labor.

(A) The contractor or subcontractor must make the records required under paragraphs (a)(3)(i) through (iii) of this section, and any other documents that the [write the name of the agency] or the Department of Labor deems necessary to determine compliance with the labor standards provisions of any of the applicable statutes referenced by § 5.1, available for inspection, copying, or transcription by authorized representatives of the [write the name of the agency] or the Department of Labor, and must permit such representatives to interview workers during working hours on the job.

(i) All laborers and mechanics employed or working upon the site of the work (or otherwise working in construction or development of the project under a development statute), will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR part 3)), the full amount of basic hourly wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, regardless of any contractual relationship which may be alleged to exist between the contractor and such laborers and mechanics. As provided in paragraphs (d) and (e) of this section, the appropriate wage determinations are effective by operation of law even if they have not been attached to the contract. Contributions made or costs reasonably anticipated for bona fide fringe benefits under the Davis-Bacon Act (40 U.S.C. 3141(2)(B)) on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (a)(1)(v) of this section; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such weekly period. Such laborers and mechanics must be paid the appropriate wage rate and fringe benefits on the wage determination for the classification(s) of work actually performed, without regard to skill, except as provided in paragraph (a)(4) of this section. Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein: Provided, That the employer's payroll records accurately set forth the time spent in each classification in which work is performed. The wage determination (including any additional classifications and wage rates conformed under paragraph (a)(1)(iii) of this section) and the Davis-Bacon poster (WH-1321) must be posted at all times by the contractor and its subcontractors at the site of the work in a prominent and accessible place where it can be easily seen by the workers.

(iii) The allowance for payment of wages to apprentices at rates less than the applicable prevailing wage rates determined by the U.S. Department of Labor is subject to any applicable ratio of apprentices to journeyworkers required under the registered apprenticeship program and consistent with section 45(b)(8)(B) and § 1.45-8. Any apprentice performing construction, alteration, or repair work on the job site in excess of the ratio permitted under the registered program or the ratio applicable to the geographic area of the facility pursuant to 29 CFR 5.5(a)(4)(i) must be paid not less than the applicable wage rate on the wage determination for the work actually performed to satisfy the Prevailing Wage Requirements. Taxpayers, contractors, or subcontractors have the discretion to determine which apprentice(s) must receive the full prevailing wage rate for hours worked if the applicable ratio of apprentices to journeyworkers has not been met.

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(a) This section sets forth the procedure for resolution of disputes of fact or law concerning payment of prevailing wage rates, overtime pay, proper classification, or monetary relief for violations of § 5.5(a)(11) or (b)(5). The procedures in this section may be initiated upon the Administrator's own motion, upon referral of the dispute by a Federal agency pursuant to § 5.5(a)(9), or upon request of the contractor or subcontractor.

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(a) In cases other than those forwarded to the Attorney General of the United States under paragraph (b) of this section where violations of the labor standards clauses contained in § 5.5 and the applicable statutes referenced by § 5.1 result in underpayment of wages to workers or monetary damages caused by violations of § 5.5(a)(11) or (b)(5), the Federal agency or an authorized representative of the Department of Labor will request that restitution be made to such workers or on their behalf to plans, funds, or programs for any type of bona fide fringe benefits within the meaning of 40 U.S.C. 3141(2)(B), including interest from the date of the underpayment or loss. Interest on any back wages or monetary relief provided for in this part will be calculated using the percentage established for the underpayment of taxes under 26 U.S.C. 6621 and will be compounded daily.

(a) This section sets forth the procedure for resolution of disputes of fact or law concerning payment of prevailing wage rates, overtime pay, proper classification, or monetary relief for violations of § 5.5(a)(11) or (b)(5). The procedures in this section may be initiated upon the Administrator's own motion, upon referral of the dispute by a Federal agency pursuant to § 5.5(a)(9), or upon request of the contractor or subcontractor.

(a) When the Administrator finds that any person has discriminated in any way against any worker or job applicant in violation of § 5.5(a)(11) or (b)(5), or caused any person to discriminate in any way against any worker or job applicant in violation of § 5.5(a)(11) or (b)(5), the Administrator will notify the person, any contractors for whom the person worked or on whose behalf the person acted, and any upper tier contractors, as well as the relevant contracting agency(ies) of the discrimination and request that the person and any contractors for whom the person worked or on whose behalf the person acted remedy the violation.

(6) The contractor or subcontractor must insert in any subcontracts the clauses contained in paragraphs (a)(1) through (11) of this section, along with the applicable wage determination(s) and such other clauses or contract modifications as the [write in the name of the Federal agency] may by appropriate instructions require, and a clause requiring the subcontractors to include these clauses and wage determination(s) in any lower tier subcontracts. The prime contractor is responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in this section. In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and may be subject to debarment, as appropriate.

(4) In accordance with normal operating procedures, the contracting agency may be furnished various investigatory material from the investigation files of the Department of Labor. None of the material, other than computations of back wages, liquidated damages, and monetary relief for violations of § 5.5(a)(11) or (b)(5), and the summary of back wages due, may be disclosed in any manner to anyone other than Federal officials charged with administering the contract or program providing Federal assistance to the contract, without requesting the permission and views of the Department of Labor.

(1) Where underpayments by a contractor or subcontractor total less than $1,000, where there is no reason to believe that the contractor or subcontractor has disregarded its obligations to workers or subcontractors, and where restitution has been effected and future compliance assured, the Federal agency need not submit its investigative findings and recommendations to the Administrator, unless the investigation or other compliance action was made at the request of the Department of Labor. In the latter case, the Federal agency will submit a factual summary report detailing any violations including any data on the amount of restitution paid, the number of workers who received restitution, liquidated damages assessed under the Contract Work Hours and Safety Standards Act, corrective measures taken (such as “letters of notice” or remedial action taken for violations of § 5.5(a)(11) or (b)(5)), and any information that may be necessary to review any recommendations for an appropriate adjustment in liquidated damages under § 5.8.

(b) The Agency Head must cause or require the contracting officer to insert the following clauses set forth in paragraphs (b)(1) through (5) of this section in full, or (for contracts covered by the Federal Acquisition Regulation) by reference, in any contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses must be inserted in addition to the clauses required by paragraph (a) of this section or 29 CFR 4.6. As used in this paragraph (b), the terms “laborers and mechanics” include watchpersons and guards.

(1) No contractor or subcontractor contracting for any part of the conract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.

(2) In the event of any violation of the clause set forth in paragraph (b)(1) of this section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages and interest from the date of the underpayment. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchpersons and guards, employed in violation of the clause set forth in paragraph (b)(1) of this section, in the sum of $33 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (b)(1).

(i) The [write in the name of the Federal agency or the recipient of Federal assistance] may, upon its own action, or must, upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the contractor so much of the accrued payments or advances as may be considered necessary to satisfy the liabilities of the prime contractor or any subcontractor for any unpaid wages; monetary relief, including interest; and liquidated damages required by the clauses set forth in this paragraph (b) on this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract subject to the Contract Work Hours and Safety Standards Act that is held by the same prime contractor (as defined in § 5.2). The necessary funds may be withheld from the contractor under this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract that is subject to the Contract Work Hours and Safety Standards Act and is held by the same prime contractor, regardless of whether the other contract was awarded or assisted by the same agency, and such funds may be used to satisfy the contractor liability for which the funds were withheld.

(ii) The Department has priority to funds withheld or to be withheld in accordance with paragraph (a)(2)(i) or (b)(3)(i) of this section, or both, over claims to those funds by:

(A) A contractor's surety(ies), including without limitation performance bond sureties and payment bond sureties;

(B) A contracting agency for its reprocurement costs;

(C) A trustee(s) (either a court-appointed trustee or a U.S. trustee, or both) in bankruptcy of a contractor, or a contractor's bankruptcy estate;

(D) A contractor's assignee(s);

(E) A contractor's successor(s); or

(F) A claim asserted under the Prompt Payment Act, 31 U.S.C. 3901-3907.

(4) The contractor or subcontractor must insert in any subcontracts the clauses set forth in paragraphs (b)(1) through (5) of this section and a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor is responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (b)(1) through (5). In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and associated liquidated damages and may be subject to debarment, as appropriate.

(5) It is unlawful for any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, or to cause any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, any worker or job applicant for:

(i) Notifying any contractor of any conduct which the worker reasonably believes constitutes a violation of the Contract Work Hours and Safety Standards Act (CWHSSA) or its implementing regulations in this part;

(ii) Filing any complaint, initiating or causing to be initiated any proceeding, or otherwise asserting or seeking to assert on behalf of themselves or others any right or protection under CWHSSA or this part;

(iii) Cooperating in any investigation or other compliance action, or testifying in any proceeding under CWHSSA or this part; or

(b) The Agency Head must cause or require the contracting officer to insert the following clauses set forth in paragraphs (b)(1) through (5) of this section in full, or (for contracts covered by the Federal Acquisition Regulation) by reference, in any contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses must be inserted in addition to the clauses required by paragraph (a) of this section or 29 CFR 4.6. As used in this paragraph (b), the terms “laborers and mechanics” include watchpersons and guards.

(1) No contractor or subcontractor contracting for any part of the conract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.

(2) In the event of any violation of the clause set forth in paragraph (b)(1) of this section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages and interest from the date of the underpayment. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchpersons and guards, employed in violation of the clause set forth in paragraph (b)(1) of this section, in the sum of $33 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (b)(1).

(i) The [write in the name of the Federal agency or the recipient of Federal assistance] may, upon its own action, or must, upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the contractor so much of the accrued payments or advances as may be considered necessary to satisfy the liabilities of the prime contractor or any subcontractor for any unpaid wages; monetary relief, including interest; and liquidated damages required by the clauses set forth in this paragraph (b) on this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract subject to the Contract Work Hours and Safety Standards Act that is held by the same prime contractor (as defined in § 5.2). The necessary funds may be withheld from the contractor under this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract that is subject to the Contract Work Hours and Safety Standards Act and is held by the same prime contractor, regardless of whether the other contract was awarded or assisted by the same agency, and such funds may be used to satisfy the contractor liability for which the funds were withheld.

(ii) The Department has priority to funds withheld or to be withheld in accordance with paragraph (a)(2)(i) or (b)(3)(i) of this section, or both, over claims to those funds by:

(A) A contractor's surety(ies), including without limitation performance bond sureties and payment bond sureties;

(B) A contracting agency for its reprocurement costs;

(C) A trustee(s) (either a court-appointed trustee or a U.S. trustee, or both) in bankruptcy of a contractor, or a contractor's bankruptcy estate;

(D) A contractor's assignee(s);

(E) A contractor's successor(s); or

(F) A claim asserted under the Prompt Payment Act, 31 U.S.C. 3901-3907.

(4) The contractor or subcontractor must insert in any subcontracts the clauses set forth in paragraphs (b)(1) through (5) of this section and a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor is responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (b)(1) through (5). In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and associated liquidated damages and may be subject to debarment, as appropriate.

(5) It is unlawful for any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, or to cause any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, any worker or job applicant for:

(i) Notifying any contractor of any conduct which the worker reasonably believes constitutes a violation of the Contract Work Hours and Safety Standards Act (CWHSSA) or its implementing regulations in this part;

(ii) Filing any complaint, initiating or causing to be initiated any proceeding, or otherwise asserting or seeking to assert on behalf of themselves or others any right or protection under CWHSSA or this part;

(iii) Cooperating in any investigation or other compliance action, or testifying in any proceeding under CWHSSA or this part; or

(a) When an overtime computation discloses underpayments, the responsible contractor or subcontractor must pay the affected employee any unpaid wages and pay liquidated damages to the Government. The contracting officer must assess liquidated damages at the rate specified at 29 CFR 5.5(b)(2) per affected employee for each calendar day on which the employer required or permitted the employee to work in excess of the standard workweek of 40 hours without paying overtime wages required by the statute. In accordance with the Federal Civil Penalties Inflation Adjustment Act of 1990 (28 U.S.C. 2461 Note), the Department of Labor adjusts this civil monetary penalty for inflation no later than January 15 each year.

(b) The Agency Head must cause or require the contracting officer to insert the following clauses set forth in paragraphs (b)(1) through (5) of this section in full, or (for contracts covered by the Federal Acquisition Regulation) by reference, in any contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses must be inserted in addition to the clauses required by paragraph (a) of this section or 29 CFR 4.6. As used in this paragraph (b), the terms “laborers and mechanics” include watchpersons and guards.

(1) No contractor or subcontractor contracting for any part of the conract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.

(2) In the event of any violation of the clause set forth in paragraph (b)(1) of this section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages and interest from the date of the underpayment. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchpersons and guards, employed in violation of the clause set forth in paragraph (b)(1) of this section, in the sum of $33 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (b)(1).

(i) The [write in the name of the Federal agency or the recipient of Federal assistance] may, upon its own action, or must, upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the contractor so much of the accrued payments or advances as may be considered necessary to satisfy the liabilities of the prime contractor or any subcontractor for any unpaid wages; monetary relief, including interest; and liquidated damages required by the clauses set forth in this paragraph (b) on this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract subject to the Contract Work Hours and Safety Standards Act that is held by the same prime contractor (as defined in § 5.2). The necessary funds may be withheld from the contractor under this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract that is subject to the Contract Work Hours and Safety Standards Act and is held by the same prime contractor, regardless of whether the other contract was awarded or assisted by the same agency, and such funds may be used to satisfy the contractor liability for which the funds were withheld.

(ii) The Department has priority to funds withheld or to be withheld in accordance with paragraph (a)(2)(i) or (b)(3)(i) of this section, or both, over claims to those funds by:

(A) A contractor's surety(ies), including without limitation performance bond sureties and payment bond sureties;

(B) A contracting agency for its reprocurement costs;

(C) A trustee(s) (either a court-appointed trustee or a U.S. trustee, or both) in bankruptcy of a contractor, or a contractor's bankruptcy estate;

(D) A contractor's assignee(s);

(E) A contractor's successor(s); or

(F) A claim asserted under the Prompt Payment Act, 31 U.S.C. 3901-3907.

(4) The contractor or subcontractor must insert in any subcontracts the clauses set forth in paragraphs (b)(1) through (5) of this section and a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor is responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (b)(1) through (5). In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and associated liquidated damages and may be subject to debarment, as appropriate.

(5) It is unlawful for any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, or to cause any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, any worker or job applicant for:

(i) Notifying any contractor of any conduct which the worker reasonably believes constitutes a violation of the Contract Work Hours and Safety Standards Act (CWHSSA) or its implementing regulations in this part;

(ii) Filing any complaint, initiating or causing to be initiated any proceeding, or otherwise asserting or seeking to assert on behalf of themselves or others any right or protection under CWHSSA or this part;

(iii) Cooperating in any investigation or other compliance action, or testifying in any proceeding under CWHSSA or this part; or

(c) Cross-withholding of funds may be requested from contracts held by other entities that may be considered to be the same prime contractor as that term is defined in § 5.2. Such cross-withholding is appropriate where the separate legal entities have independently consented to it by entering into contracts containing the withholding provisions at § 5.5(a)(2) and (b)(3). Cross-withholding from a contract held by a different legal entity is not appropriate unless the withholding provisions were incorporated in full or by reference in that different legal entity's contract. Absent exceptional circumstances, cross-withholding is not permitted from a contract held by a different legal entity where the Davis-Bacon labor standards were incorporated only by operation of law into that contract.

(b) The Agency Head must cause or require the contracting officer to insert the following clauses set forth in paragraphs (b)(1) through (5) of this section in full, or (for contracts covered by the Federal Acquisition Regulation) by reference, in any contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses must be inserted in addition to the clauses required by paragraph (a) of this section or 29 CFR 4.6. As used in this paragraph (b), the terms “laborers and mechanics” include watchpersons and guards.

(1) No contractor or subcontractor contracting for any part of the conract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.

(2) In the event of any violation of the clause set forth in paragraph (b)(1) of this section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages and interest from the date of the underpayment. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchpersons and guards, employed in violation of the clause set forth in paragraph (b)(1) of this section, in the sum of $33 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (b)(1).

(i) The [write in the name of the Federal agency or the recipient of Federal assistance] may, upon its own action, or must, upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the contractor so much of the accrued payments or advances as may be considered necessary to satisfy the liabilities of the prime contractor or any subcontractor for any unpaid wages; monetary relief, including interest; and liquidated damages required by the clauses set forth in this paragraph (b) on this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract subject to the Contract Work Hours and Safety Standards Act that is held by the same prime contractor (as defined in § 5.2). The necessary funds may be withheld from the contractor under this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract that is subject to the Contract Work Hours and Safety Standards Act and is held by the same prime contractor, regardless of whether the other contract was awarded or assisted by the same agency, and such funds may be used to satisfy the contractor liability for which the funds were withheld.

(ii) The Department has priority to funds withheld or to be withheld in accordance with paragraph (a)(2)(i) or (b)(3)(i) of this section, or both, over claims to those funds by:

(A) A contractor's surety(ies), including without limitation performance bond sureties and payment bond sureties;

(B) A contracting agency for its reprocurement costs;

(C) A trustee(s) (either a court-appointed trustee or a U.S. trustee, or both) in bankruptcy of a contractor, or a contractor's bankruptcy estate;

(D) A contractor's assignee(s);

(E) A contractor's successor(s); or

(F) A claim asserted under the Prompt Payment Act, 31 U.S.C. 3901-3907.

(4) The contractor or subcontractor must insert in any subcontracts the clauses set forth in paragraphs (b)(1) through (5) of this section and a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor is responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (b)(1) through (5). In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and associated liquidated damages and may be subject to debarment, as appropriate.

(5) It is unlawful for any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, or to cause any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, any worker or job applicant for:

(i) Notifying any contractor of any conduct which the worker reasonably believes constitutes a violation of the Contract Work Hours and Safety Standards Act (CWHSSA) or its implementing regulations in this part;

(ii) Filing any complaint, initiating or causing to be initiated any proceeding, or otherwise asserting or seeking to assert on behalf of themselves or others any right or protection under CWHSSA or this part;

(iii) Cooperating in any investigation or other compliance action, or testifying in any proceeding under CWHSSA or this part; or

(a) In cases other than those forwarded to the Attorney General of the United States under paragraph (b) of this section where violations of the labor standards clauses contained in § 5.5 and the applicable statutes referenced by § 5.1 result in underpayment of wages to workers or monetary damages caused by violations of § 5.5(a)(11) or (b)(5), the Federal agency or an authorized representative of the Department of Labor will request that restitution be made to such workers or on their behalf to plans, funds, or programs for any type of bona fide fringe benefits within the meaning of 40 U.S.C. 3141(2)(B), including interest from the date of the underpayment or loss. Interest on any back wages or monetary relief provided for in this part will be calculated using the percentage established for the underpayment of taxes under 26 U.S.C. 6621 and will be compounded daily.

(a) This section sets forth the procedure for resolution of disputes of fact or law concerning payment of prevailing wage rates, overtime pay, proper classification, or monetary relief for violations of § 5.5(a)(11) or (b)(5). The procedures in this section may be initiated upon the Administrator's own motion, upon referral of the dispute by a Federal agency pursuant to § 5.5(a)(9), or upon request of the contractor or subcontractor.

(a) When the Administrator finds that any person has discriminated in any way against any worker or job applicant in violation of § 5.5(a)(11) or (b)(5), or caused any person to discriminate in any way against any worker or job applicant in violation of § 5.5(a)(11) or (b)(5), the Administrator will notify the person, any contractors for whom the person worked or on whose behalf the person acted, and any upper tier contractors, as well as the relevant contracting agency(ies) of the discrimination and request that the person and any contractors for whom the person worked or on whose behalf the person acted remedy the violation.

(b) The Agency Head must cause or require the contracting officer to insert the following clauses set forth in paragraphs (b)(1) through (5) of this section in full, or (for contracts covered by the Federal Acquisition Regulation) by reference, in any contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses must be inserted in addition to the clauses required by paragraph (a) of this section or 29 CFR 4.6. As used in this paragraph (b), the terms “laborers and mechanics” include watchpersons and guards.

(1) No contractor or subcontractor contracting for any part of the conract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.

(2) In the event of any violation of the clause set forth in paragraph (b)(1) of this section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages and interest from the date of the underpayment. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchpersons and guards, employed in violation of the clause set forth in paragraph (b)(1) of this section, in the sum of $33 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (b)(1).

(i) The [write in the name of the Federal agency or the recipient of Federal assistance] may, upon its own action, or must, upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the contractor so much of the accrued payments or advances as may be considered necessary to satisfy the liabilities of the prime contractor or any subcontractor for any unpaid wages; monetary relief, including interest; and liquidated damages required by the clauses set forth in this paragraph (b) on this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract subject to the Contract Work Hours and Safety Standards Act that is held by the same prime contractor (as defined in § 5.2). The necessary funds may be withheld from the contractor under this contract, any other Federal contract with the same prime contractor, or any other federally assisted contract that is subject to the Contract Work Hours and Safety Standards Act and is held by the same prime contractor, regardless of whether the other contract was awarded or assisted by the same agency, and such funds may be used to satisfy the contractor liability for which the funds were withheld.

(ii) The Department has priority to funds withheld or to be withheld in accordance with paragraph (a)(2)(i) or (b)(3)(i) of this section, or both, over claims to those funds by:

(A) A contractor's surety(ies), including without limitation performance bond sureties and payment bond sureties;

(B) A contracting agency for its reprocurement costs;

(C) A trustee(s) (either a court-appointed trustee or a U.S. trustee, or both) in bankruptcy of a contractor, or a contractor's bankruptcy estate;

(D) A contractor's assignee(s);

(E) A contractor's successor(s); or

(F) A claim asserted under the Prompt Payment Act, 31 U.S.C. 3901-3907.

(4) The contractor or subcontractor must insert in any subcontracts the clauses set forth in paragraphs (b)(1) through (5) of this section and a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor is responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (b)(1) through (5). In the event of any violations of these clauses, the prime contractor and any subcontractor(s) responsible will be liable for any unpaid wages and monetary relief, including interest from the date of the underpayment or loss, due to any workers of lower-tier subcontractors, and associated liquidated damages and may be subject to debarment, as appropriate.

(5) It is unlawful for any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, or to cause any person to discharge, demote, intimidate, threaten, restrain, coerce, blacklist, harass, or in any other manner discriminate against, any worker or job applicant for:

(i) Notifying any contractor of any conduct which the worker reasonably believes constitutes a violation of the Contract Work Hours and Safety Standards Act (CWHSSA) or its implementing regulations in this part;

(ii) Filing any complaint, initiating or causing to be initiated any proceeding, or otherwise asserting or seeking to assert on behalf of themselves or others any right or protection under CWHSSA or this part;

(iii) Cooperating in any investigation or other compliance action, or testifying in any proceeding under CWHSSA or this part; or

(4) In accordance with normal operating procedures, the contracting agency may be furnished various investigatory material from the investigation files of the Department of Labor. None of the material, other than computations of back wages, liquidated damages, and monetary relief for violations of § 5.5(a)(11) or (b)(5), and the summary of back wages due, may be disclosed in any manner to anyone other than Federal officials charged with administering the contract or program providing Federal assistance to the contract, without requesting the permission and views of the Department of Labor.

(1) Where underpayments by a contractor or subcontractor total less than $1,000, where there is no reason to believe that the contractor or subcontractor has disregarded its obligations to workers or subcontractors, and where restitution has been effected and future compliance assured, the Federal agency need not submit its investigative findings and recommendations to the Administrator, unless the investigation or other compliance action was made at the request of the Department of Labor. In the latter case, the Federal agency will submit a factual summary report detailing any violations including any data on the amount of restitution paid, the number of workers who received restitution, liquidated damages assessed under the Contract Work Hours and Safety Standards Act, corrective measures taken (such as “letters of notice” or remedial action taken for violations of § 5.5(a)(11) or (b)(5)), and any information that may be necessary to review any recommendations for an appropriate adjustment in liquidated damages under § 5.8.

(4) Under any of the above circumstances, notwithstanding the requirement to incorporate the correct wage determination(s) within 30 days, the correct wage determination(s) will be effective by operation of law, retroactive to the date of award or the beginning of construction (under the National Housing Act, under section 8 of the U.S. Housing Act of 1937, or where there is no contract award), in accordance with § 5.5(e) of this subtitle.

All contracts made with respect to the construction, prosecution, completion, or repair of any public building or public work or building or work financed in whole or in part by loans or grants from the United States covered by the regulations in this part must expressly bind the contractor or subcontractor to comply with such of the regulations in this part as may be applicable. In this regard, see § 5.5(a) of this subtitle. However, these requirements will be considered to be effective by operation of law, whether or not they are incorporated into such contracts, as set forth in § 5.5(e) of this subtitle.

(F) Notwithstanding the requirement to incorporate the contract clauses and correct wage determination within 30 days, the contract clauses and correct wage determination will be effective by operation of law, retroactive to the beginning of construction, in accordance with § 5.5(e).