§1308.24. Undue delay in Contracting Officer's decision.
18 C.F.R. § 1308.24
If there is an undue delay by a Contracting Officer in issuing a decision on a claim, the Contractor may request the Chairman to direct the Contracting Officer to issue a decision within a specified period of time.
A request under this section shall—
Be in writing;
State the date on which the claim was submitted to the Contracting Officer.
State the date suggested for issuance of a decision by the Contracting Officer.
TVA may reply to a motion under this section within 5 days after its receipt.
The Chairman shall issue a written decision on the request. If granted, the decision shall specify the date by which the Contracting Officer's decision is to be rendered, and a copy shall be served on the Contracting Officer.
Notes, amendments, and revision history
Authority
Authority: Tennessee Valley Authority Act of 1933, as amended, 16 U.S.C. 831-831dd; Contract Disputes Act of 1978, 92 Stat. 2383-2391.
Source
Source: 44 FR 29648, May 22, 1979, unless otherwise noted. Redesignated at 44 FR 30682, May 29, 1979.