§7101. Definitions — Inbound Citations
41 U.S.C. § 7101
Cited by 114 provisions in release 119-102.
Citations to §7101(1)
-
(1) An Armed Services Board of Contract Appeals may be established within the Department of Defense when the Secretary of Defense, after consultation with the Administrator, determines from a workload study that the volume of contract claims justifies the establishment of a full-time agency board of at least 3 members who shall have no other inconsistent duties. Workload studies will be updated at least once every 3 years and submitted to the Administrator.
-
(A) The Civilian Board consists of members appointed by the Administrator of General Services (in consultation with the Administrator for Federal Procurement Policy) from a register of applicants maintained by the Administrator of General Services, in accordance with rules issued by the Administrator of General Services (in consultation with the Administrator for Federal Procurement Policy) for establishing and maintaining a register of eligible applicants and selecting Civilian Board members. The Administrator of General Services shall appoint a member without regard to political affiliation and solely on the basis of the professional qualifications required to perform the duties and responsibilities of a Civilian Board member.
-
(6) The Administrator, from time to time, may review the dollar amounts specified in paragraph (1) and adjust the amounts in accordance with economic indexes selected by the Administrator.
Citations to §7101(2)
-
(3) A contracting officer is not obligated to render a final decision on a claim of more than $100,000 that is not certified in accordance with paragraph (1) if, within 60 days after receipt of the claim, the contracting officer notifies the contractor in writing of the reasons why any attempted certification was found to be defective. A defect in the certification of a claim does not deprive a court or an agency board of jurisdiction over the claim. Prior to the entry of a final judgment by a court or a decision by an agency board, the court or agency board shall require a defective certification to be corrected.
-
(a) A contractor, within 90 days from the date of receipt of a contracting officer’s decision under section 7103 of this title, may appeal the decision to an agency board as provided in section 7105 of this title.
-
(1) Except as provided in paragraph (2), and in lieu of appealing the decision of a contracting officer under section 7103 of this title to an agency board, a contractor may bring an action directly on the claim in the United States Court of Federal Claims, notwithstanding any contract provision, regulation, or rule of law to the contrary.
-
(1) An Armed Services Board of Contract Appeals may be established within the Department of Defense when the Secretary of Defense, after consultation with the Administrator, determines from a workload study that the volume of contract claims justifies the establishment of a full-time agency board of at least 3 members who shall have no other inconsistent duties. Workload studies will be updated at least once every 3 years and submitted to the Administrator.
-
(i) jurisdiction over any additional category of laws or disputes over which an agency board of contract appeals established pursuant to section 8 of the Contract Disputes Act exercised jurisdiction before January 6, 2007; and
-
(ii) any other function the agency board performed before January 6, 2007, on behalf of those agencies.
-
(2) The Board of Directors of the Tennessee Valley Authority shall establish criteria for the appointment of members to the agency board established under paragraph (1), and shall designate a chairman of the agency board. The chairman and other members of the agency board shall receive compensation, at the daily equivalent of the rates determined under section 5372a of title 5, for each day they are engaged in the actual performance of their duties as members of the agency board.
-
(1) There is established an agency board of contract appeals known as the Postal Service Board of Contract Appeals.
-
(D) Each other agency board has jurisdiction to decide any appeal from a decision of a contracting officer relative to a contract made by its agency.
-
(2) In exercising this jurisdiction, an agency board may grant any relief that would be available to a litigant asserting a contract claim in the United States Court of Federal Claims or, in the event that a case is filed under chapter 38 of title 31, any relief that would be available to a litigant under that chapter.
-
(f) A member of an agency board of contract appeals may administer oaths to witnesses, authorize depositions and discovery proceedings, and require by subpoena the attendance of witnesses, and production of books and papers, for the taking of testimony or evidence by deposition or in the hearing of an appeal by the agency board. In case of contumacy or refusal to obey a subpoena by a person who resides, is found, or transacts business within the jurisdiction of a United States district court, the court, upon application of the agency board through the Attorney General, or upon application by the board of contract appeals of the Tennessee Valley Authority, shall have jurisdiction to issue the person an order requiring the person to appear before the agency board or a member of the agency board, to produce evidence or to give testimony, or both. Any failure of the person to obey the order of the court may be punished by the court as contempt of court.
-
(g) An agency board shall—(1) to the fullest extent practicable provide informal, expeditious, and inexpensive resolution of disputes;(2) issue a decision in writing or take other appropriate action on each appeal submitted; and(3) mail or otherwise furnish a copy of the decision to the contractor and the contracting officer.
-
(a) The rules of each agency board shall include a procedure for the accelerated disposition of any appeal from a decision of a contracting officer where the amount in dispute is $100,000 or less. The accelerated procedure is applicable at the sole election of the contractor. An appeal under the accelerated procedure shall be resolved, whenever possible, within 180 days from the date the contractor elects to use the procedure.
-
(1) The rules of each agency board shall include a procedure for the expedited disposition of any appeal from a decision of a contracting officer where the amount in dispute is $50,000 or less, or in the case of a small business concern (as defined in the Small Business Act (15 U.S.C. 631 et seq.) and regulations under that Act), $150,000 or less. The small claims procedure is applicable at the sole election of the contractor.
-
(2) The small claims procedure shall provide for simplified rules of procedure to facilitate the decision of any appeal. An appeal under the small claims procedure may be decided by a single member of the agency board with such concurrences as may be provided by rule or regulation.
-
(1) The decision of an agency board is final, except that—(A) a contractor may appeal the decision to the United States Court of Appeals for the Federal Circuit within 120 days from the date the contractor receives a copy of the decision; or(B) if an agency head determines that an appeal should be taken, the agency head, with the prior approval of the Attorney General, may transmit the decision to the United States Court of Appeals for the Federal Circuit for judicial review under section 1295 of title 28, within 120 days from the date the agency receives a copy of the decision.
-
(b) Notwithstanding any contract provision, regulation, or rule of law to the contrary, in an appeal by a contractor or the Federal Government from the decision of an agency board pursuant to subsection (a)—(1) the decision of the agency board on a question of law is not final or conclusive; but(2) the decision of the agency board on a question of fact is final and conclusive and may not be set aside unless the decision is—(A) fraudulent, arbitrary, or capricious;(B) so grossly erroneous as to necessarily imply bad faith; or(C) not supported by substantial evidence.
-
(1) the decision of the agency board on a question of law is not final or conclusive; but
-
(2) the decision of the agency board on a question of fact is final and conclusive and may not be set aside unless the decision is—(A) fraudulent, arbitrary, or capricious;(B) so grossly erroneous as to necessarily imply bad faith; or(C) not supported by substantial evidence.
-
(c) In an appeal by a contractor or the Federal Government from the decision of an agency board pursuant to subsection (a), the court may render an opinion and judgment and remand the case for further action by the agency board or by the executive agency as appropriate, with direction the court considers just and proper.
-
(d) If 2 or more actions arising from one contract are filed in the United States Court of Federal Claims and one or more agency boards, for the convenience of parties or witnesses or in the interest of justice, the United States Court of Federal Claims may order the consolidation of the actions in that court or transfer any actions to or among the agency boards involved.
-
(1) Whenever an action involving an issue described in paragraph (2) is pending in a district court of the United States, the district court may request an agency board to provide the court with an advisory opinion on the matters of contract interpretation under consideration.
-
(3) A district court shall direct a request under paragraph (1) to the agency board having jurisdiction under this chapter to adjudicate appeals of contract claims under the contract being interpreted by the court.
-
(4) After receiving a request for an advisory opinion under paragraph (1), an agency board shall provide the advisory opinion in a timely manner to the district court making the request.
-
(b) Any monetary award to a contractor by an agency board shall be paid promptly in accordance with the procedures contained in subsection (a).
Citations to §7101(3)
-
(c) If an agency head determines that applying this chapter would not be in the public interest, this chapter does not apply to a contract with a foreign government, an agency of a foreign government, an international organization, or a subsidiary body of an international organization.
-
(1) This section does not authorize an agency head to settle, compromise, pay, or otherwise adjust any claim involving fraud.
-
(B) if an agency head determines that an appeal should be taken, the agency head, with the prior approval of the Attorney General, may transmit the decision to the United States Court of Appeals for the Federal Circuit for judicial review under section 1295 of title 28, within 120 days from the date the agency receives a copy of the decision.
Citations to §7101(4)
-
(1) An Armed Services Board of Contract Appeals may be established within the Department of Defense when the Secretary of Defense, after consultation with the Administrator, determines from a workload study that the volume of contract claims justifies the establishment of a full-time agency board of at least 3 members who shall have no other inconsistent duties. Workload studies will be updated at least once every 3 years and submitted to the Administrator.
-
(2) Members of the Armed Services Board shall be selected and appointed in the same manner as administrative law judges appointed pursuant to section 3105 of title 5, with an additional requirement that members must have had at least 5 years of experience in public contract law. The Secretary of Defense shall designate the chairman and vice chairman of the Armed Services Board from among the appointed members. Compensation for the chairman, vice chairman, and other members shall be determined under section 5372a of title 5.
-
(A) The Armed Services Board has jurisdiction to decide any appeal from a decision of a contracting officer of the Department of Defense, the Department of the Army, the Department of the Navy, the Department of the Air Force, or the National Aeronautics and Space Administration relative to a contract made by that department or agency.
Citations to §7101(5)
-
(1) There is established in the General Services Administration the Civilian Board of Contract Appeals.
-
(A) The Civilian Board consists of members appointed by the Administrator of General Services (in consultation with the Administrator for Federal Procurement Policy) from a register of applicants maintained by the Administrator of General Services, in accordance with rules issued by the Administrator of General Services (in consultation with the Administrator for Federal Procurement Policy) for establishing and maintaining a register of eligible applicants and selecting Civilian Board members. The Administrator of General Services shall appoint a member without regard to political affiliation and solely on the basis of the professional qualifications required to perform the duties and responsibilities of a Civilian Board member.
-
(B) Members of the Civilian Board shall be selected and appointed to serve in the same manner as administrative law judges appointed pursuant to section 3105 of title 5, with an additional requirement that members must have had at least 5 years experience in public contract law. Compensation for the members shall be determined under section 5372a of title 5.
-
(3) Members of the Civilian Board are subject to removal in the same manner as administrative law judges, as provided in section 7521 of title 5.
-
(A) The Civilian Board has jurisdiction as provided by subsection (e)(1)(B).
-
(B) With the concurrence of the Federal agencies affected, the Civilian Board may assume—(i) jurisdiction over any additional category of laws or disputes over which an agency board of contract appeals established pursuant to section 8 of the Contract Disputes Act exercised jurisdiction before January 6, 2007; and(ii) any other function the agency board performed before January 6, 2007, on behalf of those agencies.
-
(2) The Postal Service Board of Contract Appeals consists of judges appointed by the Postmaster General. The judges shall meet the qualifications of and serve in the same manner as members of the Civilian Board.
-
(3) This chapter applies to contract disputes before the Postal Service Board of Contract Appeals in the same manner as it applies to contract disputes before the Civilian Board.
-
(B) The Civilian Board has jurisdiction to decide any appeal from a decision of a contracting officer of any executive agency (other than the Department of Defense, the Department of the Army, the Department of the Navy, the Department of the Air Force, the National Aeronautics and Space Administration, the United States Postal Service, the Postal Regulatory Commission, or the Tennessee Valley Authority) relative to a contract made by that agency.
Citations to §7101(6)
-
(1) Each claim by a contractor against the Federal Government relating to a contract shall be submitted to the contracting officer for a decision.
-
(3) Each claim by the Federal Government against a contractor relating to a contract shall be the subject of a written decision by the contracting officer.
-
(3) A contracting officer is not obligated to render a final decision on a claim of more than $100,000 that is not certified in accordance with paragraph (1) if, within 60 days after receipt of the claim, the contracting officer notifies the contractor in writing of the reasons why any attempted certification was found to be defective. A defect in the certification of a claim does not deprive a court or an agency board of jurisdiction over the claim. Prior to the entry of a final judgment by a court or a decision by an agency board, the court or agency board shall require a defective certification to be corrected.
-
(d) The contracting officer shall issue a decision in writing and shall mail or otherwise furnish a copy of the decision to the contractor.
-
(e) The contracting officer’s decision shall state the reasons for the decision reached and shall inform the contractor of the contractor’s rights as provided in this chapter. Specific findings of fact are not required. If made, specific findings of fact are not binding in any subsequent proceeding.
-
(1) A contracting officer shall issue a decision on any submitted claim of $100,000 or less within 60 days from the contracting officer’s receipt of a written request from the contractor that a decision be rendered within that period.
-
(2) A contracting officer shall, within 60 days of receipt of a submitted certified claim over $100,000—(A) issue a decision; or(B) notify the contractor of the time within which a decision will be issued.
-
(3) The decision of a contracting officer on submitted claims shall be issued within a reasonable time, in accordance with regulations prescribed by the agency, taking into account such factors as the size and complexity of the claim and the adequacy of information in support of the claim provided by the contractor.
-
(4) A contractor may request the tribunal concerned to direct a contracting officer to issue a decision in a specified period of time, as determined by the tribunal concerned, in the event of undue delay on the part of the contracting officer.
-
(5) Failure by a contracting officer to issue a decision on a claim within the required time period is deemed to be a decision by the contracting officer denying the claim and authorizes an appeal or action on the claim as otherwise provided in this chapter. However, the tribunal concerned may, at its option, stay the proceedings of the appeal or action to obtain a decision by the contracting officer.
-
(g) The contracting officer’s decision on a claim is final and conclusive and is not subject to review by any forum, tribunal, or Federal Government agency, unless an appeal or action is timely commenced as authorized by this chapter. This chapter does not prohibit an executive agency from including a clause in a Federal Government contract requiring that, pending final decision of an appeal, action, or final settlement, a contractor shall proceed diligently with performance of the contract in accordance with the contracting officer’s decision.
-
(1) Notwithstanding any other provision of this chapter, a contractor and a contracting officer may use any alternative means of dispute resolution under subchapter IV of chapter 5 of title 5, or other mutually agreeable procedures, for resolving claims. All provisions of subchapter IV of chapter 5 of title 5 apply to alternative means of dispute resolution under this subsection.
-
(A) A contracting officer who rejects a contractor’s request for alternative dispute resolution proceedings shall provide the contractor with a written explanation, citing one or more of the conditions in section 572(b) of title 5 or other specific reasons that alternative dispute resolution procedures are inappropriate.
-
(a) A contractor, within 90 days from the date of receipt of a contracting officer’s decision under section 7103 of this title, may appeal the decision to an agency board as provided in section 7105 of this title.
-
(1) Except as provided in paragraph (2), and in lieu of appealing the decision of a contracting officer under section 7103 of this title to an agency board, a contractor may bring an action directly on the claim in the United States Court of Federal Claims, notwithstanding any contract provision, regulation, or rule of law to the contrary.
-
(3) A contractor shall file any action under paragraph (1) or (2) within 12 months from the date of receipt of a contracting officer’s decision under section 7103 of this title.
-
(A) The Armed Services Board has jurisdiction to decide any appeal from a decision of a contracting officer of the Department of Defense, the Department of the Army, the Department of the Navy, the Department of the Air Force, or the National Aeronautics and Space Administration relative to a contract made by that department or agency.
-
(B) The Civilian Board has jurisdiction to decide any appeal from a decision of a contracting officer of any executive agency (other than the Department of Defense, the Department of the Army, the Department of the Navy, the Department of the Air Force, the National Aeronautics and Space Administration, the United States Postal Service, the Postal Regulatory Commission, or the Tennessee Valley Authority) relative to a contract made by that agency.
-
(C) The Postal Service Board of Contract Appeals has jurisdiction to decide any appeal from a decision of a contracting officer of the United States Postal Service or the Postal Regulatory Commission relative to a contract made by either agency.
-
(D) Each other agency board has jurisdiction to decide any appeal from a decision of a contracting officer relative to a contract made by its agency.
-
(3) mail or otherwise furnish a copy of the decision to the contractor and the contracting officer.
-
(a) The rules of each agency board shall include a procedure for the accelerated disposition of any appeal from a decision of a contracting officer where the amount in dispute is $100,000 or less. The accelerated procedure is applicable at the sole election of the contractor. An appeal under the accelerated procedure shall be resolved, whenever possible, within 180 days from the date the contractor elects to use the procedure.
-
(1) The rules of each agency board shall include a procedure for the expedited disposition of any appeal from a decision of a contracting officer where the amount in dispute is $50,000 or less, or in the case of a small business concern (as defined in the Small Business Act (15 U.S.C. 631 et seq.) and regulations under that Act), $150,000 or less. The small claims procedure is applicable at the sole election of the contractor.
-
(2) An issue referred to in paragraph (1) is any issue that could be the proper subject of a final decision of a contracting officer appealable under this chapter.
-
(1) Interest on an amount found due a contractor on a claim shall be paid to the contractor for the period beginning with the date the contracting officer receives the contractor’s claim, pursuant to section 7103(a) of this title, until the date of payment of the claim.
-
(2) On a claim for which the certification under section 7103(b)(1) of this title is found to be defective, any interest due under this section shall be paid for the period beginning with the date the contracting officer initially receives the contractor’s claim until the date of payment of the claim.
Citations to §7101(7)
-
(1) Each claim by a contractor against the Federal Government relating to a contract shall be submitted to the contracting officer for a decision.
-
(2) Each claim by a contractor against the Federal Government relating to a contract shall be in writing.
-
(3) Each claim by the Federal Government against a contractor relating to a contract shall be the subject of a written decision by the contracting officer.
-
(A) Each claim by a contractor against the Federal Government relating to a contract and each claim by the Federal Government against a contractor relating to a contract shall be submitted within 6 years after the accrual of the claim.
-
(B) Subparagraph (A) of this paragraph does not apply to a claim by the Federal Government against a contractor that is based on a claim by the contractor involving fraud.
-
(1) For claims of more than $100,000 made by a contractor, the contractor shall certify that—(A) the claim is made in good faith;(B) the supporting data are accurate and complete to the best of the contractor’s knowledge and belief;(C) the amount requested accurately reflects the contract adjustment for which the contractor believes the Federal Government is liable; and(D) the certifier is authorized to certify the claim on behalf of the contractor.
-
(B) the supporting data are accurate and complete to the best of the contractor’s knowledge and belief;
-
(C) the amount requested accurately reflects the contract adjustment for which the contractor believes the Federal Government is liable; and
-
(D) the certifier is authorized to certify the claim on behalf of the contractor.
-
(2) The certification required by paragraph (1) may be executed by an individual authorized to bind the contractor with respect to the claim.
-
(3) A contracting officer is not obligated to render a final decision on a claim of more than $100,000 that is not certified in accordance with paragraph (1) if, within 60 days after receipt of the claim, the contracting officer notifies the contractor in writing of the reasons why any attempted certification was found to be defective. A defect in the certification of a claim does not deprive a court or an agency board of jurisdiction over the claim. Prior to the entry of a final judgment by a court or a decision by an agency board, the court or agency board shall require a defective certification to be corrected.
-
(2) If a contractor is unable to support any part of the contractor’s claim and it is determined that the inability is attributable to a misrepresentation of fact or fraud by the contractor, then the contractor is liable to the Federal Government for an amount equal to the unsupported part of the claim plus all of the Federal Government’s costs attributable to reviewing the unsupported part of the claim. Liability under this paragraph shall be determined within 6 years of the commission of the misrepresentation of fact or fraud.
-
(d) The contracting officer shall issue a decision in writing and shall mail or otherwise furnish a copy of the decision to the contractor.
-
(e) The contracting officer’s decision shall state the reasons for the decision reached and shall inform the contractor of the contractor’s rights as provided in this chapter. Specific findings of fact are not required. If made, specific findings of fact are not binding in any subsequent proceeding.
-
(1) A contracting officer shall issue a decision on any submitted claim of $100,000 or less within 60 days from the contracting officer’s receipt of a written request from the contractor that a decision be rendered within that period.
-
(B) notify the contractor of the time within which a decision will be issued.
-
(3) The decision of a contracting officer on submitted claims shall be issued within a reasonable time, in accordance with regulations prescribed by the agency, taking into account such factors as the size and complexity of the claim and the adequacy of information in support of the claim provided by the contractor.
-
(4) A contractor may request the tribunal concerned to direct a contracting officer to issue a decision in a specified period of time, as determined by the tribunal concerned, in the event of undue delay on the part of the contracting officer.
-
(g) The contracting officer’s decision on a claim is final and conclusive and is not subject to review by any forum, tribunal, or Federal Government agency, unless an appeal or action is timely commenced as authorized by this chapter. This chapter does not prohibit an executive agency from including a clause in a Federal Government contract requiring that, pending final decision of an appeal, action, or final settlement, a contractor shall proceed diligently with performance of the contract in accordance with the contracting officer’s decision.
-
(1) Notwithstanding any other provision of this chapter, a contractor and a contracting officer may use any alternative means of dispute resolution under subchapter IV of chapter 5 of title 5, or other mutually agreeable procedures, for resolving claims. All provisions of subchapter IV of chapter 5 of title 5 apply to alternative means of dispute resolution under this subsection.
-
(2) The contractor shall certify the claim when required to do so under subsection (b)(1) or other law.
-
(A) A contracting officer who rejects a contractor’s request for alternative dispute resolution proceedings shall provide the contractor with a written explanation, citing one or more of the conditions in section 572(b) of title 5 or other specific reasons that alternative dispute resolution procedures are inappropriate.
-
(B) A contractor that rejects an agency’s request for alternative dispute resolution proceedings shall inform the agency in writing of the contractor’s specific reasons for rejecting the request.
-
(a) A contractor, within 90 days from the date of receipt of a contracting officer’s decision under section 7103 of this title, may appeal the decision to an agency board as provided in section 7105 of this title.
-
(1) Except as provided in paragraph (2), and in lieu of appealing the decision of a contracting officer under section 7103 of this title to an agency board, a contractor may bring an action directly on the claim in the United States Court of Federal Claims, notwithstanding any contract provision, regulation, or rule of law to the contrary.
-
(2) In the case of an action against the Tennessee Valley Authority, the contractor may only bring an action directly on the claim in a district court of the United States pursuant to section 1337 of title 28, notwithstanding any contract provision, regulation, or rule of law to the contrary.
-
(3) A contractor shall file any action under paragraph (1) or (2) within 12 months from the date of receipt of a contracting officer’s decision under section 7103 of this title.
-
(3) mail or otherwise furnish a copy of the decision to the contractor and the contracting officer.
-
(a) The rules of each agency board shall include a procedure for the accelerated disposition of any appeal from a decision of a contracting officer where the amount in dispute is $100,000 or less. The accelerated procedure is applicable at the sole election of the contractor. An appeal under the accelerated procedure shall be resolved, whenever possible, within 180 days from the date the contractor elects to use the procedure.
-
(1) The rules of each agency board shall include a procedure for the expedited disposition of any appeal from a decision of a contracting officer where the amount in dispute is $50,000 or less, or in the case of a small business concern (as defined in the Small Business Act (15 U.S.C. 631 et seq.) and regulations under that Act), $150,000 or less. The small claims procedure is applicable at the sole election of the contractor.
-
(3) An appeal under the small claims procedure shall be resolved, whenever possible, within 120 days from the date the contractor elects to use the procedure.
-
(4) A decision against the Federal Government or against the contractor reached under the small claims procedure is final and conclusive and may not be set aside except in cases of fraud.
-
(A) a contractor may appeal the decision to the United States Court of Appeals for the Federal Circuit within 120 days from the date the contractor receives a copy of the decision; or
-
(A) a contractor may appeal the decision to a United States district court pursuant to section 1337 of title 28, within 120 days from the date the contractor receives a copy of the decision; or
-
(b) Notwithstanding any contract provision, regulation, or rule of law to the contrary, in an appeal by a contractor or the Federal Government from the decision of an agency board pursuant to subsection (a)—(1) the decision of the agency board on a question of law is not final or conclusive; but(2) the decision of the agency board on a question of fact is final and conclusive and may not be set aside unless the decision is—(A) fraudulent, arbitrary, or capricious;(B) so grossly erroneous as to necessarily imply bad faith; or(C) not supported by substantial evidence.
-
(c) In an appeal by a contractor or the Federal Government from the decision of an agency board pursuant to subsection (a), the court may render an opinion and judgment and remand the case for further action by the agency board or by the executive agency as appropriate, with direction the court considers just and proper.
-
(b) Any monetary award to a contractor by an agency board shall be paid promptly in accordance with the procedures contained in subsection (a).
-
(2) Notwithstanding subsections (a) to (c), any monetary award to a contractor by the board of contract appeals of the Tennessee Valley Authority shall be paid in accordance with section 9(b) of the Tennessee Valley Authority Act of 1933 (16 U.S.C. 831h(b)).
-
(1) Interest on an amount found due a contractor on a claim shall be paid to the contractor for the period beginning with the date the contracting officer receives the contractor’s claim, pursuant to section 7103(a) of this title, until the date of payment of the claim.
-
(2) On a claim for which the certification under section 7103(b)(1) of this title is found to be defective, any interest due under this section shall be paid for the period beginning with the date the contracting officer initially receives the contractor’s claim until the date of payment of the claim.
Citations to §7101(8)
-
(a) Unless otherwise specifically provided in this chapter, this chapter applies to any express or implied contract (including those of the nonappropriated fund activities described in sections 1346 and 1491 of title 28) made by an executive agency for—(1) the procurement of property, other than real property in being;(2) the procurement of services;(3) the procurement of construction, alteration, repair, or maintenance of real property; or(4) the disposal of personal property.
-
(g) The contracting officer’s decision on a claim is final and conclusive and is not subject to review by any forum, tribunal, or Federal Government agency, unless an appeal or action is timely commenced as authorized by this chapter. This chapter does not prohibit an executive agency from including a clause in a Federal Government contract requiring that, pending final decision of an appeal, action, or final settlement, a contractor shall proceed diligently with performance of the contract in accordance with the contracting officer’s decision.
-
(B) The Civilian Board has jurisdiction to decide any appeal from a decision of a contracting officer of any executive agency (other than the Department of Defense, the Department of the Army, the Department of the Navy, the Department of the Air Force, the National Aeronautics and Space Administration, the United States Postal Service, the Postal Regulatory Commission, or the Tennessee Valley Authority) relative to a contract made by that agency.
-
(c) In an appeal by a contractor or the Federal Government from the decision of an agency board pursuant to subsection (a), the court may render an opinion and judgment and remand the case for further action by the agency board or by the executive agency as appropriate, with direction the court considers just and proper.
Citations to §7101(9)
-
(2) If a contractor is unable to support any part of the contractor’s claim and it is determined that the inability is attributable to a misrepresentation of fact or fraud by the contractor, then the contractor is liable to the Federal Government for an amount equal to the unsupported part of the claim plus all of the Federal Government’s costs attributable to reviewing the unsupported part of the claim. Liability under this paragraph shall be determined within 6 years of the commission of the misrepresentation of fact or fraud.